Terms &
Conditions

1. Acceptance of Terms

By accessing our website or engaging Hindustan Signages for any service, you agree to be bound by these Terms of Service.

2. Services

Hindustan Signages provides signage manufacturing, retail store fabrication, custom fixtures, and related branding services, governed by individual project quotations or contracts.

3. Quotations & Orders

• All quotations are valid for 15 days from the date of issue.
• A project commences only upon receipt of written confirmation and advance payment.
• Changes to scope after confirmation may result in revised pricing and timelines.
• Prices are exclusive of applicable GST unless stated otherwise.

4. Payment Terms

• Typically, a 50% advance is required before production begins, with the balance due prior to delivery.
• We accept bank transfers, UPI, and cheque payments in favour of Hindustan Signages.
• Delayed payments may result in project delays or suspension of work.

5. Delivery & Installation

• Delivery timelines are estimates and may vary based on complexity and site conditions.
• The client is responsible for ensuring site readiness for installation.
• Risk of damage passes to the client upon delivery to the specified location.

6. Warranty

• 1-year warranty on manufacturing defects for all signage and fabrication work.
• LED components carry a 2-year warranty.
• Warranty excludes damage from misuse, improper third-party installation, or natural events.

7. Intellectual Property

All designs remain our property until full payment is received. We retain the right to showcase completed projects in our portfolio unless the client requests otherwise in writing.

8. Client Responsibilities

• Provide accurate site dimensions, approved artwork, and all necessary local authority approvals.
• Errors from incorrect client information will be rectified at the client's cost.

9. Limitation of Liability

Our total liability shall not exceed the total amount paid by the client for the specific project. We are not liable for indirect, incidental, or consequential damages.

10. Cancellation Policy

• Cancellations must be communicated in writing.
• If production has commenced, the advance payment is non-refundable.
• Materials ordered specifically for a project cannot be returned.

11. Governing Law

These terms are governed by the laws of India. Any disputes shall be subject to the exclusive jurisdiction of the courts in New Delhi.

12. Contact Us